BUILD WITH CONFIDENCE FIND OUT MORE

Terms & Conditions

Ownership

This website is owned and managed by Dennis Family Homes. In these terms and conditions, the expressions ‘we’, ‘us’ and ‘our’ are a reference to Dennis Family Homes Pty Ltd ABN 83 056 254 249 and includes our related entities.

Access

These terms and conditions apply to the use of this website, including the use of the information services offered on this website. In using this website, you agree to be bound by these terms and conditions. If you do not accept these terms and conditions, you must refrain from using the website.

Website

All information provided by us on this website is general information and is not in the nature of advice.

We derive the information on our website from sources which we believe to be accurate and up to date as at the date of publication. We nevertheless reserve the right to update this information at any time. In addition, we do not make any representations or warranties that the information we provide on the website is reliable, accurate or complete or that your access to that information will be uninterrupted, timely or secure.

We are not liable for any loss resulting from any action taken or reliance made by you on any information or material posted by us on the website. You should make your own enquiries and seek independent advice from relevant professionals before acting or relying on any information or material contained on our website.

You agree to use our website for lawful purposes only.

Home Designs, House and Land Packages – Descriptions and Prices

Images, drawings, floorplans, sizes and areas, materials and fittings displayed on this website are for illustrative purposes only and may include options available at extra cost. Actual specifications for a particular home may vary and will be set out in the specific building contract. Due to estate and council requirements, lot widths indicated may alter and should be used as a guide only.

Unless expressed to the contrary, all price information is for homes constructed in the Melbourne metropolitan areas. Alternative prices apply to regional areas including the Geelong, Shepparton, Ballarat, Bendigo, Albury/Wodonga, Echuca, Wagga Wagga and Griffith regions. A surcharge applies to areas outside of these regions.

Final package prices depend upon a range of variable factors outside our control including council building approvals and planning consent, finance, soil test and survey results and the final plans, specifications, fixtures and materials selected.

Home is not built yet. All illustrations and descriptions have been prepared in good faith and with due care. Facades and images are representative only and to be used as a guide. Alterations and price changes may occur without notice after the date of printing. Site costs are not fixed unless specified. Fixed site costs refers to site fall, connection costs and rock removal only. Dennis Family Homes reserves its right to alter designs, inclusions and options without notice.

Package offered is subject to land availability which may change at any time without notice, and is not available in conjunction with any other promotional offer.

________________________________________________________________________________________________

PROMOTIONS

Aspirations Rapid Promotion

The Aspirations Rapid promotion is available on Aspirations Series 1 (until 30 April 2024) and Aspirations Series 2 homes with standard inclusions. This promotion will run from 1 March 2024 until 30 June 2024 (Promotion Period) unless extended.

To be eligible, the customer must:

  • have registered and titled land, or title must occur within 60 days of payment of initial fee and signing of the Authority to Proceed document;
  • choose an Aspirations Series home standard floorplan and façade (customer must not request structural changes to the standard floorplan or changes to windows or external doors, except for those outlined in the pre-selected structural design upgrades schedule – see your Sales Consultant for details);
  • choose from a pre-selected set of standard structural design upgrades – see your Sales Consultant for details;
  • choose from a pre-selected set of home upgrades – Refer brochure for details.
  • choose from a pre-selected set of colour schedules – Refer brochure for details.

Dennis Family Homes will use all reasonable endeavours to prepare building contracts for eligible customers within five weeks from submission of documentation deemed by DFH to be ‘final and complete sales paperwork’.  

“Rapid” Customers will not attend Showroom colour appointments. Your Sales Consultant will detail the selection process and provide costings. Where referred to, “fixed site costs” means site costs referrable to site fall, connection costs and rock removal. Fixed site costs exclude retaining walls. Contract price for homes under the Aspiration Rapid Promotion is fixed, provided progress payments are made on time and there are no subsequent variations, whether agreed or required to comply with changed laws.

This offer is subject to stock availability and any approved upgrades are in lieu of standard items. Items cannot be substituted unless otherwise specified in the building contract. Customers will not be entitled to exchange for cash or credit at contract and this offer may not be used in conjunction with any other Dennis Family Homes promotions unless stated otherwise.

Dennis Family Homes reserves the right to amend its designs and inclusions or the promotion without notice at any time, including modifying specified products, brands, and models with the discretion to substitute items of comparable style, quality, and price as necessary. Dennis Family Homes makes every reasonable effort to ensure the accuracy of the information provided, however, as supply conditions and other factors may change, we make no warranties as to accuracy and accept no liability for errors or omissions.

All images and photographs used are for illustrative purposes only and may differ from final built forms. Images throughout may show upgrades or items not supplied as part of the promotion or subject to additional cost, including inbuilt cabinetry, landscaping, decking, garage doors, fencing, furniture, decorator items, window furnishings, feature tiling, splashback windows, entertainer stacker doors, skylights, decorative indoor and outdoor screens and light fittings. Please see our Sales Consultant for detailed costing.

Details on the website are not a contract, please check your New Home Contract for full binding terms and conditions.

All rights reserved. Copyright © 2024 Dennis Family Intellectual Property Pty Ltd.

Dennis Family Homes Pty Ltd ACN   056 254 249 is a Registered Building Practitioner. Builder License Number CDB-U 49195 (VIC) and 173511C (NSW).

 

Move In Ready Aspirations Homes Offer

‘Move-in-ready. Pay no more. So Good!’ promotion is available on Aspirations Series 1 and Aspirations Series 2 homes with standard inclusions. This promotion is only available to new deposits taken from 1st January 2024 to 31 March 2024 unless extended and is subject to stock availability. The Aspirations ‘Move-in-ready. Pay no more. So Good!’ offer includes all items listed below for no additional cost or buy-in payment. Aspirations ‘Move-in-ready. Pay no more. So Good!’

Driveway

Concrete driveway, portico and path to front door Choice of coloured concrete paving to driveway, portico and path to front door up to 35m2 OR natural concrete paving to driveway, portico and path to front door up to 45m2.

Cooling

Bonaire Optima 3.5kw L-Series high wall split system air conditioner with remote including back to back installation, isolation switch and drainage overflow point. Note – Subject to room area and location suitability. External unit located on concrete or plastic base pad(s) with internal head unit mounted internally on external wall. Indoor unit width 855mm. This unit is recommended for conditioned space up to 28m2 with shaded windows or heavy drapes.

Clothesline

Daytek slimline fold down wall mount clothesline. 2400mm x 700mm (nominal) including wall mount installation. Note – The Owner is to meet with Dennis Family Homes Project Supervisor on site to confirm the exact position location requirement of this clothes line.

Complete Flooring Pack 2

Series 1 timber look laminate to entry through to kitchen, meals and family areas and Series 1 carpet to remaining areas (wet areas remain standard ceramic floor tiles. Series 2
carpet to double storey homes).

Dishwasher

Technika® TDX8SS-6 600mm fully integrated dishwasher. Internet connection Developer guidelines dependent.

Either NBN or Opticom.

NBN package inclusion;
• P25 Tele conduit including drawstring from the premises connection device to the fibre wall outlet connection in the garage.
• Clipsal 3105PEN7440 internal communications box.
• 1 x ‘Clipsal 2000 Series’ telephone point (CATe 6 cable).
• 1 x ‘Clipsal 2000 Series’ data point (CATe 6 cable).
• 1 x ‘Clipsal 2000 Series’ double power point.
Opticom FTTH package inclusion;
• P25 tele conduit including drawstring from side of house near metre box to garage.
• 1 x 6mm earth wire from side of house to metre box.
• 1 x 24 strand 0.40 gauge low voltage cable from side of house near metre box to garage.
• 1 x RJ6 cable run from side of house to TV point.
• 1 x satellite splitter.
• 2 x telephone points (CATe 6 cable).
• 1 x data point (CATe 6 cable).

Blinds

Category 1 Single Blockout Roller Blinds – Lovelight single blockout roller blinds throughout dwelling in blockout fabric. Package covers single roller blinds up to 2410mm wide. Where windows & sliding doors exceed 2410mm in width Lovelight will provide 2No. blinds (dependent on the break up of glass within the application). All roller blinds to windows will be installed in the reveal of the window frame and fabric will be back rolled. All roller blinds to sliding doors will be installed on face (of the architrave) and fabric will be back rolled. Some blinds may be front rolled if there is an obstruction, this is determined at site measure at Lovelights discretion. Please note: No furnishings will be installed to: void windows, entry side light windows, kitchen windows above cooktop, within shower cubicles, fully tiled window reveals, onto hinged doors & stairwell windows.

Letterbox

Monaco letterbox with reinforced concrete pillar in grey or brown colour finish. Dennis Family Homes reserves the right to modify specified products, brands, and models outlined, with the discretion to substitute items of comparable style, quality, and price as necessary. All prices advertised are based on specified build regions and do not include land, or associated site-specific costs (which can only be estimated by the Builder at contract stage upon gaining access to the site) and structural upgrades or structural changes to master floorplan, facade upgrades, developer guidelines and Bushfire Attack Level (BAL) costs. All prices are current at time of publication. Please see our Sales Consultant for more detailed cost estimates.

Aspirations Series 1 homes:
3-bedroom single storey homes price refers to Aspirations Series 1 Crystal 16 with Livia façade.

4-bedroom single storey homes price refers to Aspirations Series 1 Ekati 23BF with Livia Façade.

4-bedroom double storey homes price refers to Aspirations Series 1 Topaz 25 with Livia façade.

^Aspirations Titled Land promotional offer:
• Promotion is only available to the first 50 customers per calendar month during the promotional period with registered and titled land (or titling by 30 April 2024) who deposit on Aspirations Series 1 and Aspirations Series 2 homes from 12 February 2024 to 30 March 2024 (unless extended) and is subject to stock availability.
• Essential information under Clause 13 of HIA building contracts must be supplied within 18 weeks of signing Authority To Proceed & the customer must not delay site start beyond 1 October 2024
• Offer not transferable for cash or credit at contract and may only be used in conjunction with the previous outlined ‘Move- in-Ready. Pay no more. So Good’ promotion and not used in
conjunction with any other offer.
• Customers eligible for the Aspirations Titled Land promotional offer will receive items listed below for no additional cost or buy-in payment:
Aspirations ‘Title land promotional offer’ 900mm Technika® Appliance Upgrade Pack Provide 900mm wide appliance package upgrade in the kitchen comprising of the following in lieu of the standard 600mm wide appliances:
• Electric underbench oven – Technika T948SS-6 black glass and stainless steel 900mm 10 function programmable electric underbench oven.
• Gas cooktop – Technika TGC9GLWFSS 900mm stainless steel 5 burner gas cooktop including left hand wok burner (provided your nominated build lot allows gas installation).
• Canopy rangehood – Technika CHEM52C9CL-5 900mm stainless steel canopy rangehood. 20mm Caesarstone® Benchtop to Bathroom and Ensuite Provide Series 2 Standard Range Caesarstone with 20mm edge to benchtop in lieu of standard laminate benchtop. Note – Excludes waterfall ends and power point cut outs. 20 LED (9W) downlights Provide additional 20No LED (9W) downlights to areas indicated on plans. Laundry – laminated base cabinetry Provide laminate base cabinetry (up to 900mm wide) to Laundry with 33mm laminate benchtop, Everhard Nugleam Benchline (71245) 45 litre stainless steel inset trough with by-pass, Alder Aiko 96090 chrome mixer tapset and 200mm high ceramic wall tiling. Note – Not available to Crystal 16 and Ekati 25 homes due to design constraints.

Dennis Family Homes reserves the right to modify specified products, brands, and models outlined, with the discretion to substitute items of comparable style, quality, and price as necessary.
All images and photographs used are for illustrative purposes only and may differ from final built forms.Images throughout may show upgrades or items not supplied as part of the promotion or subject to additional cost, including inbuilt cabinetry, landscaping, decking, garage doors, fencing, furniture, decorator items, window furnishings, feature tiling, splashback windows, entertainer stacker doors, skylights, decorative indoor and outdoor screens and light fittings. Lot depth and width specifications for any floorplans are subject to fall of land and Council requirements. Floorplans and dimensions may alter depending on the façade chosen and may not reflect developer guidelines. Total size on floorplans is calculated by measuring from external walls. If the home
design is modified, additional charges may apply. Dennis Family Homes reserves the right to substitute unavailable products with products of similar make and kind. Please check your New Home Contract for full binding terms and conditions. Dennis Family Homes reserves the right to amend its designs and inclusions without notice.

All rights reserved. © 2024 Dennis Family Intellectual Property Pty Ltd. Dennis Family Homes Pty Ltd ACN 056 254 249 is a Registered Building Practitioner. Builder License Number CDB-U 49195 (VIC). DFH10056 – Plus.

$40K Your Way Inspirations Homes Offer

The Inspirations “$40K Your Way” Promotion is available to Inspirations Series homes (Premium and Essence ranges only), and explicitly excludes Inspirations Elegance, Indulgence and Aspirations Series homes. Offer subject to buy-in payment, see details below. Only one upgrade offer may be chosen per home. This promotion is only available to new holding deposits taken under a preliminary agreement signed 1st January 2024 to 31st March 2024, unless extended, and is subject to stock availability. Offer not transferable for cash or credit at contract (irrespective of any unused promotion credit amounts) and may not be used in conjunction with any other offer.

Pay $7,990 for up to $40,000 worth of specified upgrades. Customers who pay $7,990 under this offer will receive up to $40,000 worth of specified upgrades to their new Inspirations Series Dennis Family Home. The $40,000 worth of upgrades can only be used on standard upgrade and Showroom items currently available in Dennis Family Homes’ variance price book and cannot be used for any non- standard structural upgrades, site costs or any other non-standard items. All upgrades are in lieu of standard inclusions. Talk with your Sales Consultant for detailed information about available items to upgrade. Pricing and values may vary depending on house type and building location, please see our Sales Consultant for detailed costing.

^Inspirations Titled Land promotional offer:
• Promotion is only available to the first 50 customers per calendar month during the promotional period with registered and titled land (or titling by 30 April 2024) who deposit on Inspirations Series homes (Premium and Essence ranges only) from 12 February 2024 to 30 March 2024 (unless extended) and is subject to stock availability.
• Essential information under Clause 13 of HIA building contracts must be supplied within 18 weeks of signing Authority To Proceed & the customer must not delay site start beyond 1 October 2024
• Offer not transferable for cash or credit at contract and may only be used in conjunction with the previous outlined ‘$40K Your Way’ promotion and not used in conjunction with any other offer.
• Customers eligible for the Inspirations Titled Land promotional offer will receive a $10,000 Harvey Norman voucher as an e-gift card, to be delivered within 60 days of confirmation that the
Base Stage progress payment has been paid within the payment terms Dennis Family Homes reserves the right to modify specified products, brands, and models outlined, with the discretion to substitute items of comparable style, quality, and price as necessary.

All images and photographs used are for illustrative purposes only and may differ from final built forms. Images throughout may show upgrades or items not supplied as part of the promotion or
subject to additional cost, including inbuilt cabinetry, landscaping, decking, garage doors, fencing, furniture, decorator items, window furnishings, feature tiling, splashback windows, entertainer
stacker doors, skylights, decorative indoor and outdoor screens and light fittings. Please see our Sales Consultant for detailed costing.

Details on the website are not a contract and Dennis Family Homes reserves the right to alter the promotion and offerings at any time. If the home design is modified, additional charges may apply. Dennis Family Homes reserves the right to substitute unavailable products with products of similar make and kind. Please check your New Home Contract for full binding terms and conditions.
Dennis Family Homes makes every reasonable effort to ensure the accuracy of the information provided, however, as supply conditions and other factors may change, we make no warranties as
to accuracy and accept no liability for errors or omissions.

All rights reserved. Copyright © 2024 Dennis Family Intellectual Property Pty Ltd. Dennis Family Homes Pty Ltd ACN 056 254 249 is a Registered Building Practitioner. Builder License Number CDB-U 49195 (VIC) and 173511C (NSW). DFH10048 PLUS

Knockdown Rebuild $40K Upgrade

The Dennis Family Homes “Knockdown Rebuild Inspirations Series 3 + 4 Elegance & Indulgence” promotion (“Promotion”) is available to Inspirations Series 3 + 4 Elegance & Indulgence products only (“Eligible Products”). The promotion cannot be used in conjunction with any other offer or promotions.

The Promotion is only available for customers who enter into a preliminary agreement and pay an initial fee on Eligible Products from 6 January 2024 to 31 March 2024 unless extended. Dennis Family Homes reserves the right to substitute unavailable or discontinued products with products of similar make and kind at its sole discretion. This offer is not transferable for cash or credit at contract (irrespective of any unused Promotion credit amounts) and may not be used in conjunction with any other offer.

All upgrades are in lieu of standard products. Pricing and values may vary depending on house type and building location, additional charges apply to modifications from standard plans. Please see our Knockdown Rebuild Specialists for detailed costings and queries. Our Knockdown Rebuild Specialist will provide an estimate price only and final pricing will be set out in your New Home Contract.

Customers who pay $7,990 under this offer will receive up to $40,000 worth of specified upgrades to their new Inspirations Series 3 + 4 Elegance & Indulgence Dennis Family Home.

Details on website are not a contract and Dennis Family Homes reserves the right to amend its designs and inclusions or the Promotion terms without further notice at any time. Please check your New Home Contract for full binding terms and conditions. While Dennis Family Homes makes every reasonable effort to ensure the accuracy of the information provided on publication, we make no warranties as to accuracy and accept no liability for errors or omissions as supply conditions and other factors may change.

All images and photographs used are for illustrative purposes only and may differ from final built forms. Images throughout may show upgrades not part of this promotion or items not supplied by Dennis Family Homes including inbuilt cabinetry, landscaping, decking, driveway, fencing, furniture, decorator items, window furnishings and decorative indoor and outdoor screens and light fittings (unless otherwise specified). Images throughout may also show items including feature tiling, splashback windows, garage door finishes, entertainer stacker doors and skylights that may incur additional cost.

All rights reserved. Copyright © 2024 Dennis Family Intellectual Property Pty Ltd.

ACN 125 258 237. Registered Building Practitioner. Builder License Number CDB-U 49195 (VIC) and 173511C (NSW). DFH10099

 

2023 Design Runout Sale

*2023 Design Run Out Sale promotion is available on Aspirations Series 1 and Inspirations Series 3 homes with standard inclusions. This promotion is only available to eligible customers who sign an Authority to Proceed and pay an Initial Fee to DFH before 30 April 2024. Offer not transferable for cash or credit at contract. All prices quoted are based on specified build regions and exclude land and associated site specific costs and upgrades. Please see a sales consultant for detailed pricing in your build region. Eligibility conditions for Aspirations Series 1 and Inspirations Series 3 homes:
(i) Homes available for sale as part of this promotion until 30 April 2024 on titled land only, to ensure you have signed an Authority to Proceed and paid your initial Fee to DFH prior to the National Construction Code 2022 (NCC) cutoff date of 1st May 2024;
(ii) Structural variations not permitted under this offer; purchaser requests for variations or changes to the home design may result in this offer being withdrawn, should DFH consider that the requested changes will result in delays to production of your New Home Contract;
(iii) Planning and Council requirements may result in this offer being withdrawn should necessary changes delay the production of your New Home Contract; and
(iv) This offer is strictly subject to you signing an Authority to Proceed and paying your Initial Fee to DFH prior to 1 May 2024 and additionally your appointed Building Surveyor must agree to grant DFH a discretionary exemption under section 10 of the Building Act 1993 (Vic) from compliance with NCC 2022. Should these conditions not be met, DFH reserves its right not to proceed or otherwise adjust any prices quoted in accordance with your New Home Contract.

All images and photographs used are for illustrative purposes only and may differ from final built forms. Images throughout may show upgrades or items not supplied as part of the promotion or subject to additional cost, including inbuilt cabinetry, landscaping, decking, garage doors, fencing, furniture, decorator items, window furnishings, feature tiling, splashback windows, entertainer stacker doors, skylights, decorative indoor and outdoor screens and light fittings.

Lot depth and width specifications for any floorplans are subject to fall of land and Council requirements. Floorplans and dimensions may alter depending on the façade chosen and may not reflect developer guidelines. Total size on floorplans is calculated by measuring from external walls. If the home design is modified, additional charges may apply. Dennis Family Homes reserves the right to substitute unavailable products with products of similar make and kind.

Please check your New Home Contract for full binding terms and conditions.

Dennis Family Homes reserves the right to amend its designs and inclusions without notice. All rights reserved. © 2024 Dennis Family Homes Pty Ltd. Registered Building Practitioner. Builder License Number CDB-U 49195 (VIC). DFH10044

__________________________________________________________________________________________________________________________________

DFH10234_Merrifield DV Builder Exclusive Offer_7 March to April 30, 2024.

Promotional period: 7 March 2024 to 30 April 2024

The following promotions are offered to customers who visit the Merrifield estate and who make an initial payment under a preliminary agreement with Dennis Family Homes, through a Merrifield Sales Consultant, between 7 March and 30 April 2024:

  1. Visit Merrifield estate between 7 March and 30 April 2024 and enter into a preliminary agreement and pay an initial fee for an Aspirations Series home with a Dennis Family Homes Merrifield Sales Consultant by 30 April 2024 and receive a $10k discount off the price of the home. Can be used in conjunction with the current ‘Move In Ready*’ promotion. No other offers or discounts apply; or,
  2. Visit Merrifield estate between 7 March and 30 April 2024 and enter into a preliminary agreement and pay an initial fee for an Inspirations Series home with a Dennis Family Homes Merrifield Sales Consultant by 30 April 2024 and receive a $20k discount off the price of the home. Can be used in conjunction with the current ‘$40 Your Way*’ promotion. No other offers or discounts apply.

*Terms and Conditions apply. Unless otherwise stated, this offer cannot be used in conjunction with any other Dennis Family Homes offers and no further discounts apply. All rights reserved. Copyright © 2024 Dennis Family Intellectual Property Pty Ltd. Dennis Family Homes Pty Ltd ACN 056 254 249 is a Registered Building Practitioner. Builder License Number CDB-U 49195 (VIC). DFH10234.

_____________________________________________________________________________________________

Homebuilder Grant 

Eligibility rules for the HomeBuilder grant are set by the Federal and State Governments.  You can access more information on the Treasury Coronavirus Economic Response website (https://treasury.gov.au/coronavirus/homebuilder).

Customers acknowledge and agree that DFH (including its employees, contractors and related entities) has not at any time made any warranties or representations regarding any Customer’s eligibility for the HomeBuilder grant.  This includes building commencement timeframes and any other relevant eligibility criteria pertaining to the HomeBuilder grant.

By participating in this promotion, Customers acknowledge and agree that they have made all necessary enquiries and sought independent advice on the terms and conditions of the promotion before participating.  To the extent permitted by law, the Customer releases and indemnifies DFH, its officers, employees, representatives, agents and contractors from all losses, claims or damages suffered, incurred or resulting from or in connection with their participation in this promotion.

All rights reserved. © Dennis Family Intellectual Property Homes Pty Ltd. Registered Building Practitioner. Builder Licence Number CDB-U 49195 (VIC) and 173511C (NSW).

Rebuild

All images are used for illustrative purposes only. Images may include options/upgrades and items not supplied by Dennis Family Homes such as decking, landscaping, fencing, retaining walls, water features, paving, driveway, window furnishings, light fittings, furniture and decorator items unless otherwise specified. Dennis Family Homes reserves the right to amend its designs and inclusions without notice at any time. Refer to a sales consultant or dennisfamily.com.au for additional terms and conditions. Reproduction in part or whole is forbidden. Dennis Family Homes Pty Ltd (ABN 83 056 254 249).


Display Homes Sale

*Price correct as at the time of publishing, effective as at 23 October 2013. Images are used for illustrative purposes only. In some cases rendered images of the facade option have been displayed in the absence of photography. For specific details/allowances relating to this home refer to Dennis Family Homes Sales Consultant for the working drawings in Colour Schedules. Not in conjunction with any other offer. All rights reserved.


Virtual Tours

The virtual tours depict a display home with features, fixtures and finishes that may be above standard specification or not supplied. Floorplan may not be available in all build regions and may not suit all blocks. Please see our Sales Consultant for detailed information.

Disclaimer of Liability

We do not accept any responsibility for any loss or damage, however caused which you may directly or indirectly suffer in connection with your use of this website or any linked website, nor do we accept any responsibility for any such loss arising out of your use of or reliance on information contained on or accessed through this website.

To the extent permitted by law, any condition or warranty which would otherwise be implied into these terms and conditions is hereby excluded. Where legislation implies any condition or warranty, and that legislation prohibits us from excluding or modifying the application of, or our liability under, any such condition or warranty, that condition or warranty will be deemed included but our liability will be limited for a breach of that condition or warranty to one or more of the following:

(a) if the breach relates to goods: the replacement of the goods or the supply of equivalent goods, or the repair of such goods, or the payment of the cost of replacing the goods or of acquiring equivalent goods, or the payment of the cost of having the goods repaired; and

(b) if the breach relates to services: the supplying of the services again, or the payment of the cost of having the services supplied again.

Any exclusion or limitation of liability set out in these terms and conditions or on the website does not attempt or purport to exclude liability arising under statute if, and to the extent, that such liability cannot be lawfully excluded.


Specific Warnings

You must ensure that your access to this website is not illegal or prohibited by laws which apply to you.

You must take your own precautions to ensure that the process which you employ for accessing this website does not expose you to the risk of viruses, malicious computer code or other forms of interference which may damage your own computer system. We do not accept responsibility for any interference or damage to your own computer system which arises in connection with your use of this website or any linked website.

We do not warrant the accuracy, adequacy or completeness of any information contained on this website, nor do we undertake to keep this website updated. We do not accept responsibility for loss suffered as a result of reliance by you upon the accuracy or currency of information contained on this website.

Where the information made available on this website contains opinions or judgements of third parties: you acknowledge that any opinions or advice by third parties on this website remain the responsibility of those third parties and we do not guarantee the accuracy, completeness or usefulness of that content or its fitness for any particular purpose; we do not purport to endorse the contents of that opinion or advice nor the accuracy or reliability of that opinion or advice; and we do not accept liability for loss or damage caused by your reliance upon any information obtained through this service and it remains your responsibility to evaluate the accuracy, completeness and usefulness of any such information.

Responsibility for the content of any advertisements appearing on this website (including hyperlinks to advertisers’ own websites) rests solely with the advertisers. The placement of such advertisements does not constitute a recommendation or endorsement by us of the advertisers’ products and each advertiser is solely responsible for any representations made in connection with its advertisement.


Intellectual Property Rights

You accept that the intellectual property rights subsisting in all materials on this website are owned or licensed by us and that you gain no interest in relation to them. Such rights include rights relating to this website’s look and feel, idea and concept, and confidential information, whether or not they are reduced to material or tangible form. You must not do anything, or omit to do anything, which may infringe our intellectual property rights except where expressly authorised by these terms and conditions.


Copyright

Copyright in this website (including text, architectural plans and drawings, graphics, logos, icons, sound recordings and software) is owned or licensed by us. Information procured from a third party may be the subject of copyright owned by that third party.

Other than for the purposes of, and subject to the conditions prescribed under the Copyright Act 1968 and except as expressly authorised by these terms and conditions, you may not in any form or by any means:

adapt, reproduce, communicate, store, distribute, print, display, perform, publish or create derivative works from any part of this website, or commercialise any information, products or services obtained from any part of this website, without our written permission or, in the case of third party material, from the owner of the copyright in that material.


Trademarks

Except where otherwise specified, any word or device to which is attached the TM or ® symbol is a trademark.
If you use any of our trademarks in reference to our activities, products or services, you must include a statement attributing that trademark to us. You must not use any of our trademarks:

in or as the whole or part of your own trademarks, or in connection with activities, products or services which are not ours, or in a manner which may be confusing, misleading or deceptive, or in a manner that disparages us or our products or services (including this website).


Restricted Use

Unless we agree otherwise in writing, you are provided with access to this website only for your personal use.

You are authorised to print a copy of any information contained on this website for your personal use, unless such printing is expressly prohibited.

You may not without our written permission on-sell information obtained from this website.


Linked Websites

This website may contain links to other websites. Those links are provided for convenience only and may not remain current or be maintained.
We are not responsible for the content or privacy practices associated with linked websites.

Our links with linked websites should not be construed as an endorsement, approval or recommendation by us of the owners or operators of those linked websites, or of any information, graphics, materials, products or services referred to or contained on those linked websites, unless and to the extent stipulated to the contrary.

You must not link to any part of this website other than the www.dennisfamily.com.au home page without our written consent.


Google Adwords Remarketing Policy

Dennis Family Homes are using Remarketing codes with Google Analytics to advertise online. Third-party vendors, including Google, shows Dennis Family Homes ads on sites across the Internet. Dennis Family Homes and third-party vendors, including Google, use first-party cookies (such as the Google Analytics cookie) and third-party cookies (such as the DoubleClick cookie) together to inform, optimize, and serve ads based on someone’s past visits to the Dennis Family Homes website.


Privacy Policy

These terms and conditions must be read in conjunction with our privacy policy. We undertake to comply with the terms of our privacy policy which can be accessed on this website by clicking on the following link privacy policy.

When you visit this website, our Internet service provider makes a record of your visit, and collects certain information for statistical purposes, such as your server address and domain name.

This website makes use of cookies to make your access to this website more convenient.

The personal information which we collect in the course of your visit to our website is set out in full in our privacy policy which can be accessed on this website by clicking on the following link privacy policy


Security of Information

Unfortunately, no data transmission over the Internet can be guaranteed to be totally secure. Whilst we strive to protect such information, we do not warrant and cannot ensure the security of any information which you transmit to us. Accordingly, any information which you transmit to us is transmitted at your own risk. Nevertheless, once we receive your transmission, we will take reasonable steps to preserve the security of such information.


Termination of Access

Access to this website may be terminated at any time by us without notice. Our disclaimer will nevertheless survive any such termination.


Governing Law

These terms and conditions are governed by the laws in force in the State of Victoria, Australia. Where permitted by law, you agree to submit to the exclusive jurisdiction of the courts of Victoria, Australia and any courts which may hear appeals from those courts in respect of any proceedings in connection with these terms and conditions of use or the use of this website.


Six Star

All standard designs include a six star minimum energy rating (Victoria). This is based on a standard home only. Any changes to the design may incur additional costs to reach six star.


General

We may update or amend these Terms & Conditions and our Privacy Policy from time to time. The then current version of the Terms & Conditions and Privacy Policy will apply each time you use our website.

We accept no liability for any failure to comply with these terms and conditions where such failure is due to circumstances beyond our reasonable control.

If we waive any rights available to us under these terms and conditions on one occasion, this does not mean that those rights will automatically be waived on any other occasion.

If any of these terms and conditions are held to be invalid, unenforceable or illegal for any reason, the remaining terms and conditions shall nevertheless continue in full force.


Dennis Connect

By proceeding to use the Dennis Connect service, you agree to the terms set out below in addition to the Movinghub terms of service www.movinghub.com.au/terms (together the “Terms”). If you do not accept these Terms, you may not use the Dennis Connect service.

1.     Dennis Connect is a collaborative offering by Dennis Family Homes Pty Ltd (“DFH”) and MM8 Pty Ltd (“Movinghub”). Our webpage is an information guide only and we recommend that you seek professional advice before purchasing any of the services featured. We will make our best efforts to provide relevant and correct information, however we make no warranty or representation about the fitness or suitability of any service featured on this site.  Nothing in the site shall be deemed to constitute financial advice to induce you to purchase services from the service providers. DFH does not accept liability for any errors or omission, and reserves the right to change information given at any time.

2.      DFH is only a conduit and organizer of information supplied by Movinghub and third party service providers. We are not ourselves the provider of any services or utilities.  We are not liable for any variances in quality from the information supplied to us by these third parties.

3.      Before deciding to hire any service provider, you must rely solely on your own evaluation of the service provider, including track record, qualifications, credentials, reviews, account information, representations made and such other material facts as you, in your sole discretion, deem relevant.  

4.      When you hire a service provider, the contract for that service will be between you and the service provider, and not DFH.  We will not be deemed in any way a party or a third party beneficiary of the service contract.  We have no participation in, or control over, the service transaction.  The performance, implementation, completion or payment in respect of any contracted services shall be separately arranged between the customer and service provider to the exclusion of DFH, and the customer and service provider shall look solely to the other in respect of any relevant liability, responsibility or obligation.

5.      DFH has no influence on the acceptance of any contract by the service provider and as such cannot be held liable should an offer be withdrawn or not made available to you.

6.      DFH does not accept liability for any indirect or consequential loss arising out of the use of, or connected with this service, or for any services selected through this service. We cannot guarantee that a service provider will be able to provide a particular product at any particular time or that a product will be available from day to day. We reserve the right to withdraw any service provider (or any product or service of a service provider) from our service at any time.

7.      Payments for the service providers’ services will be made direct to the service providers under their terms & conditions. We assume no responsibility for organising or making payments to the service providers.

8.      We will have no liability in respect of any other website or page on the Internet accessible from this site.

Disputes

9.      Customers dissatisfied with services performed by a third party service provider must communicate directly with the service provider to resolve and settle any problems.  We are not obligated to provide any mediation, arbitration or other dispute resolution services between customers and service providers.

10.  In exchange for the services provided by this site, and other good and valuable consideration, the receipt and sufficiency of which is acknowledged, you expressly agree to release DFH, its officers, directors, affiliates, parent companies, employees and service providers from any claims, demands, causes of action, losses and damages (direct and consequential) of every kind and nature, known and unknown, suspected and unsuspected, disclosed and undisclosed, arising out of or in any way connected with any dispute between you and any service provider.  You waive any limitations on general releases under applicable law.  Without limiting the generality of the foregoing, you release and absolve us from any liability arising from any negligence, dishonesty, fraud, swindling, deceit or misrepresentation by any service providers.  

General

11.  These terms are governed by, and construed in accordance with, the laws of Victoria, Australia.

12.  You acknowledge DFH may be paid a fee based on the services you select.

13.  You agree that you have read and accept our Privacy Policy www.dennisfamily.com.au/privacy-policy

Contact Details

If you would like further information, please contact us via email at marketing@denniscorp.com.au

__________________________________________________________________________________________________